Contact

 PAINTING WORK CONTRACT AGREEMENT FORM

This Agreement is made on this ____ day of ______, 20, between:

Contractor Name: PaintWorx
Registered Address: _________________________________________
Authorized Representative: _________________________________
Contact No.: _____________________
Email ID: _________________________

AND

Client Name: ___________________________________________
Address of Work Site: _______________________________________
Contact No.: _____________________
Email ID: _________________________

---

1. SCOPE OF WORK

The Contractor agrees to carry out the following works as per the client's requirement:

S. No	Description of Work	Area (Sqft)	Rate per Sqft (INR)	Amount (INR)
1
2
3
4
5
6
7
8
9
10

Total Project Cost: ₹ _____________________

---

2. MATERIAL SUPPLY

Please select one:
☐ Client will supply all required materials
☐ Contractor will supply all required materials

---

3. ATTACHMENTS CHECKLIST

Please tick the documents attached:
☐ Site Photographs
☐ Client ID Proof
☐ Approved Brand/Colour Code
☐ Advance/Full Payment Receipt
☐ Any other document: _____________________________________

---

4. WORK DURATION & TIMELINE

• Start Date: ____ / ____ / ______

• Completion Date: ____ / ____ / ______

• Total Estimated Days: ________________

---

5. PAYMENT TERMS

• Total Amount: ₹ _____________________

• Advance Payment (Minimum 40%): ₹ __________________

• Mid Work Payment (40%): ₹ __________________

• Final Payment (20%): ₹ __________________

• Mode of Payment: ☐ UPI ☐ Bank Transfer ☐ Cash

---

6. TERMS & CONDITIONS

A. MATERIAL & WORK QUALITY

• All materials used will be of standard quality or as approved by the client.

• Work will be performed as per professional standards.

• Contractor is not responsible for any damage post-completion.

B. WATER & ELECTRICITY SUPPLY

• Client must ensure continuous availability of water and electricity during the work period.

C. ACCESS TO SITE

• Client shall provide full and unhindered access to the work site.

D. WARRANTY

• Touch-up and minor rectifications will be handled within 30 days after handover.

E. DELAYS

• Delay due to weather, material shortage (client-supplied), or third-party obstruction shall not be borne by the Contractor.

F. TERMINATION CLAUSE

• Either party can terminate the agreement with 3 days’ written notice. Completed work must be paid for by the client.

G. LIABILITY

• Contractor shall not be held liable for structural damages, existing faults, or any unrelated accidents at the site.

H. LEGAL JURISDICTION

• Any legal disputes shall be subject to the jurisdiction of the courts located in ________________________.

---

7. SITE EQUIPMENT RESPONSIBILITY

In case the painting work requires elevation beyond the normal reach of the painter, the following equipment may be necessary for safe and efficient execution:

• Ladder

• Stool

• Scaffolding / Climber

• Safety Harness (if applicable)

Responsibility for providing the above-mentioned equipment shall be as follows:
(✓ Tick the applicable option)

☐ Client (Site Owner) will provide the necessary equipment.
☐ Contractor will arrange and provide the equipment.
☐ Equipment to be hired through third-party rental service (charges applicable and to be added in quotation).

⚠️ Note: All equipment must be safe, stable, and in working condition prior to work commencement.

Any delay or accident due to equipment non-availability or failure will not be the responsibility of the Contractor, unless previously agreed in writing.

✅ Additional Client Responsibility:

The Client shall ensure that access to elevated areas (walls, ceilings, façade, etc.) is safe, unobstructed, and ready for work before the scheduled date of commencement.

---

8. IN WITNESS WHEREOF

Both parties agree to the terms and conditions and sign this agreement voluntarily.

Contractor
Signature: ___________________________
Name: ___________________________
Date: ____ / ____ / ______

Client
Signature: ___________________________
Name: ___________________________
Date: ____ / ____ / ______

---

Stamp and seal (if any)

---

NOTE: This contract becomes valid only upon signature by both parties and receipt of advance payment as agreed.